Command Palette
Search for a command to run...
Expert Report — Pinnacle Scheduling Analysis (Draft)
In ReviewWork ProductHold - Do Not Destroyv2.0
Search for a command to run...
Superior Court of Fulton County
Civil Action File No. GDOT-LIT-2026-0148
A time-impact analysis of the as-built critical path demonstrates that 51 of the 84 days claimed by the contractor are concurrent with contractor-caused delays in the drainage structure sequence.
[ Remaining content of this PDF is not rendered in the prototype. The production viewer renders the full document with text selection, annotation and Bates numbering through the Acrobat integration. ]
Respectfully submitted,
Simone Carrow
Georgia Department of Transportation, Office of Legal Services
Tags